BHARAT HYDRO POWER CORPN. LTD. AND ORS. v. STATE OF ASSAM AND ANR

Citation: [2004] 1 S.C.R. 284

Court: Supreme Court of India

Bench: ASHOK BHAN, S.B. SINHA

Case summary

BHARAT HYDRO POWER CORPN. LTD. AND ORS. v. STATE OF ASSAM AND ANR.pdf

Judgment text

BHARAT HYDRO POWER CORPN. LTD. AND ORS. '( l v. STATE OF ASSAM AND ANR. JANUARY 7, 2004 [ASHOK BHAN AND S. B. SINHA, JJ. ] t"'i Constitution ofIndia-Articles 245, 246 & 254; Entry 56 oflist I; Entry 17 oflist II and Entries 38 & 42 oflist Ill to the Seventh Schedule-Indian Electricity Act, 1910-Sections 6, 7, & 7A-Electricity (Supply) Act, 1948- Sections 2(4A) 2(6), 26A-Bharat Hydro Power Corporation Limited (Acquisition and Transfer ofUndertaking) Act, 1996-State Act meant to take over appellant's power pr n of India sanctioned a proposal of the State Electricity Board for construction of a Hydro Electric Power project at an estimated cost of Rs. 36. 36 crores. The project could not be completed in time owing to the failure of local contra1:tors. The State Government, following the policy of privatisation adopted by the Central Government in power sector, decided to transfer the project to a joint sector company.

Memorandum of Undertaking (MOU) was entered into by the Board with appellant no. 2. The appellant no. I, after its incorporation could complete the project within the stipulated time. The Board terminated and repudiated the MOU on the failure of appellant No. I to complete the work within the extended period. .. The State on account of the inordinate delay in the completion of the project and to safeguard the public interest by completing the project as early as possible due to acute power shortage in the State, promulgated the Bharat Hydro Power Corporation Limited (Acquisition and Transfer of Undertaking) Act, 1996 acquiring the undertaking of appellant No. I. The State Government by a Notification transferred to and vested the project in the Board. .. ,,- ' Appellants filed writ petitions before High Court challenging the BHARAT HYDRO POWER CORPN. LTD. v.

STATE 285 legality anil constitutional validity of the Act being ultra vires and violative of Articles 14 and 19 (I) (g) of the Constitution of India. A Single Judge of the High Court struck down the Act holding that the State Act falls under Entry 38 of List Ill of Seventh Schedule to the Constitution of India which is already covered· hy Central Acts viz. the Indian Electricity Act, 1910 (Act of 1910) and Electricity (Supply) Act, 1948 (Act of 1948); and that the State Legislature is not competent to enact laws repugnant to the Central laws under the same Entry. In Writ appeals by the State and the • 1 Board, the High Court held the State Act to be intra vires on the ground that it falls under Entry 17 of List II and therefore not repugnant to the Central legislation.

In appeal to this Court, the appellants contended that the State Act falls under Entry 38 of List Ill of the Seventh Schedule to the Constitution of India; that the two Central Acts are already operating in the same field and the appellants are governed under the Central Acts; that there are provisions under the Act of 1910 for compulsory purchase of undertakings produci:1g electricity; that they are deemed licences being a 'Generating Company' under the Act of 1948; that the State Act creates a procedure parallel to the existing procedure provided under the Act of 1910 & 1948 and hence the State Act is bad in law as it transgresses the Central Acts and therefore repugnant to the Central Acts under Article 254 of the Constitution of India.

The respondents contended that in pith and substance, the State Act is not repugnant to the Central Acts as they operate in different fields; that the State Act is enacted to acquire the undertaking, whereas both the Central Acts have mad~ general provisions with regard to supply and use of electrical energy; and that the appellants were not licensees under the Central Acts and hence the State has the jurisdiction and power to acquire any property for public purposes making necessary provisions for payment of compensation. Dismissing the appeals, the Court HELD: I. I. The Bharat Hydro Power Corporation Limited (Acquisition and Transfer of Undertaking) Act, 1996 has been enacted to take over the Bharat Hydro Power Corporation in public interest as it could not complete the project within time so that the State could efficiently supervise, manage and execute the work expeditiously to subserve the common good in the context of the acute power shortage in the Stnte.

The State after taking over the project had the power to hand y~ it over to the State Electricity Board for completing the project. Provision has been made to pay adequate compensation which is to be determined by a Commission constituted under the Act. There is no substance in the contention of the appellants that under the Central Acts, there are specific provisions for compulsory purchase of undertaking and that the State Act hos created a parallel procedure for purchase of the undertaking thereby impinging on the Ceutral Acts. 1299-F-H; 300-AI 'r ' 1. 2. The provisions of the Indian Electricity Act, 1910 are applicable to the licensees under the Act. The appellants are not licensees under the Act. Since the appellants have not been given a license and are not licensees, Section 6 of the Act would not apply. Under Section 6, there is an 'option' "'ith the Board to purchase. The word 'option' leaves two courses open to the authority, i. e.

, either to purchase an undertaking or to renew the license. Either of the two courses would not be available as appellant No. 1 is not a licensee. Since the appellants are not the licensees, they would not be covered under any of the provisions dealing with the sale or purchase of undertaking as provided under the Act of 1910. The benefit of Sections 7 and 7A of the Act shall also not be available because it speaks of an undertaking of a licensee. As the appellants are not covered by the provisions of the Act of 1910, the State Act, which seeks to take over the appellants' undertaking and make provisions for compensation, would not be repugnant to any of the provisions of the Act of 1910. 1301-G; 302-A-C[ 1. 3.

The impugned Act and the Central Acts (Acts of 1910 and 1948) operate in two different fields without encroaching upon each other's field in as much as the true nature and character of the State Act is to acquire the undertaking and pay compensation as provided in the Act whereas '>both the Central Acts have made general provisions with regard to supply and use of electrical energy. The provisions regarding purchase of ' undertaking in the Indian Electricity Act, 1910 would not be applicable as the appellants are not lice! 'sees within the meaning of the Act of 1910. There is not even a semblance of conflict what to talk of direct conflict between the impugned State Act and the Central Acts to bring about the situation where"one cannot be obeyed without disobeying the others. Both the Acts can operate simultaneously as they do not occupy the same field. . ,, As the enactments operate in two different fields without encroaching upon each other's fields there is no repugnancy.

Since there is no repugnancy ' BHARAT llYDRO POWER CORPN. LTD. v. STATE [BHAN. . I. ] 287 f '( the question of the State Act being kept for the consideration of the President or receiving his assent did not arise. (304-F-H; 305-AI Southern Pharmaceuticals & Chemicals v. State ofKera/a, AIR (1981) SC 1863; State ofRajasthan v. G. Chawla, AIR (1959) SC 544; Thakur Amar Singh v. State ofRajasthan, 119551 2 SCR 303 Delhi Cloth and General Mills Co. Ltd. v. Union of India, AIR (1983) SC 937; fliJay Kumar Sharma and Ors. v. State ofKarnataka and Ors. , AIR (1990) SC 2072; Shyamakant Lal v. Rambha/an Singh and Ors. , AIR (1939) FC 74; Deepchand v. State ofU. P. , ~ '""'! AIR (1959) SC 648 and M. Karunanidhi v. Union ofIndia, AIR (1979) SC 898, referred to. CIVIL APPELLATE JURISDICTION: Civil Appeal Nos. 6487-6488 of 1998. From the Judgment and Order dated 21. 9. 1998 of the Gauhati High Court at Assam in W. A. Nos. 460 and 464 of 1997. V. R. Reddy, Vijay Hansaria, Sushi! Kumar Jain, A. P.

Dhamija, S. Borthakur, Jayesh K. U. , J. R. Luwang, V. K. Sidtharan, Ms. Asha G. Nair and Ms. Krishna Sarma for the appearing parties. ~ The Judgment of the Court was delivered by BHAN, J. These appeals are directed against a common judgment passed by the Division Bench of the High Court of Gauhati wherein the Division Bench while setting aside the judgment of the learned Single Judge dated 19th July, 1997 has dismissed the writ petition filed by the appellants. The writ petition was filed by the appellants challenging the constitutional validity of the Bharat Hydro Power Corporation Limited (Acquisition and Transfer of Undertaking) Act, 1996 being Assam Act I of 1997 published in the Assam -t· Gazette Extraordinary dated 6th January, 1997.

• Facts: In tlie year 1979, the Planning Commission of India sanctioned proposal of the Assam State Electricity Board (hereinafter referred to as 'the Board') for construction of a Hydro Electric Power Station in the District of Karbi Anglong on the river Barapani at an estimated cost of Rs. 36. 36 crorcs. ~ The project comprised construction of 51 meter high concrete dam on the " river Barapani near Hatidubi for utilising flow of water from catchment area of 1178 Sq. km. The installed capacity (If the project was 2 x 50 MW. The dam was to be conipleted in the year 1986, but due to the failure of the local Y• contractor, the project could not be completed and the Board terminated the contract and protracted litigation ensued. In the year 1992, after termination of the contract as aforesaid, the project was entrusted to National Project Construction Corporation (in short 'NPCC'), but the similar fate followed and Board had to terminate their contract as well in December, 1992.

In the mean time, cost of the project initially sanctioned at Rs. 36. 36 crores rose to Rs. 189. 90 crores. Out of the 'r • aforesaid estimate, the work completed was of about Rs. 116 crores and the Board needed about Rs. 60 crores to complete the project excluding other liabilities. The Board could not generate the additional fund required for completing the project. The Central Government in the year 1992-93 accepted the policy of privatisation even in the power sector. The State Government following the policy of privatisation of the Central Government decided to transfer the project to joint sector. On 25th March, 1993, Memorandum of Undertaking (MOU) was signed between the Board, Government of Assam and Mis Subhash Project and Marketing Limited (SPML), appellant No. 2 herein. According to the said MOU, SPML was to promote a new company to complete the project. In terms of the said MOU a new company under the name and style of Mis.

Bharat Hydro Power Corporation Limited (hereinafter referred to as 'appellant No. I') came into existence in which the equity participation was as follows: ASEB (the Board) 11% SPML (appellant No. 2) 40% ~ General Public 49% f On 8th April, 1993 the Deed of Assignment was executed between tht> Board and the appellant No. I, in terms of which all the assets and liabilities of the project were transferred to appellant No. I w. e. f. 8. 4. 1993. In terms of the said Deed of Assignment appellant No. I was to complete the project and start generation by June, 1995 which was subsequently extended to June, 1996. Disputes arose between the parties. According to Board as well as the 'y' ~ State ofAssam, the appellant No. I after its incorporation failed to take charge of the project till 5th April, 1994. Even after taking over of the project, the BHARAT HYDRO POWER CORPN. LTD. v. STATE [BHAN. J. ] 289 ~.. , I appellant No.

I could not achieve any progress towards completion of the project due to serious lapses and negligence on its part. On the other hand, appellants Nos. I & 2 put the entire blame on the Board and the State Government for the delay in the progress of the project. On 20th December, 1995, appellant No. I filed a suit being TS No. 244/ 96 in the Court of the Assistant District Judge No. I, Guwahati for specific performance of the contract against the Board alleging that the Board was }l remiss in the performance of its obligation under the MOU and the Deed of Assignment. Board filed an application for stay of suit in view of arbitration clause. Appellant No. I filed an application in the High Court under Sections 8 and 11 of the Arbitration and Conciliation Act, 1996 for appointment of Arbitrator to decide pending disputes between the parties. On 27th May, 1996, Board wrote to appellant No. I that due to the failure of the appellant No.

I to complete the work within the extended period, the MOU was liable to be terminated and repudiated. On 30th November, 1996 the State of Assam, keeping in view, the inordinate delay in the completion of the project and to safeguard the public interest by completing the project as early as possible in the context of acute power shortage in the State, promulgated Bharat Hydro Power Corporation Limited ( Acquisition and Transfer of Undertaking) Ordinance, 1996 acquiring the undertaking of Karbi Langpi Project of appellant No. I. The Ordinance was subsequently replaced by Bharat Hydro Power Corporation Limited (Acquisitio1: and Transfer of Undertaking) Act, 1996 (hereinafter referred to • as 'the Act'). On Ist December, 1996, the State Government by Notification transferred to and vested the said project in the Board. After the said notification the possession of the project was handed over to the Board in the presence of the representatives of the both sides on 2nd December, 1996.

On -"" 5th December, 1996 Memorandum of handing over and taking over was signed. Thereafter writ petitions being CR 6/97 and CR 283/97 were filed in J~ the High Court of Assam challenging the legality and validity ofthe Ordinance and the Act. In the writ petitions the appellants challenged the constitutional validity of the Act being ultra vires and violative of Articles 14 and 19 (l)(g) of the Constitution of India and on the ground of being vague. unfair and arbitrary. t It was prayed that the Act be struck down· being unconstitutional and beyond " the legislative powers of the State and/or is inoperative and void in law on the grounds mentioned in the writ petitions. ' A The Preamble of the Act reads as follows: "ASSAM ACT NO.

I OF 1997 (Received the Assent of the Governor on 6th January, 1997) THE BHARAT HYDRO POWER CORPORATION LIMITED (ACQUISITION AND TRANSFER OF UNDERTAKING) ACT, 1996 AN ACT l' • To provide for the acquisition, in the public interest, of the right, title and interest ofthe undertaking ofthe Bharat Hydro Power Corporation Limited and for matters connected therewith or incidental thereto. WHEREAS the Bharat Hydro Power Corporation Ltd.

, having its registrred office in the State of Assam, has been engaged for speedy execution and completion ofthe Karbi Langpi (Lower Barapani) Hydro Electric Project for ensuring supply of electricity in the State of Assam in vi(:w of the chronic shortages of power in the State; Whereas it was agreed upon in the Memorandum of Understanding entered into between the Government of Assam, the Assam State ""' Electricity Board and the Mis Subhas Project and Marketing Limited on 25th March, 1993 that the project would be completed and would be commissioned by the month of June, 1995; And whereas the company failed in the sole object ofspeedy execution • of the project within the specified time; Whereas it is expedient in the public interest that the unde11aking of the Bharat Hydro Power Corporation Limited should be acquired for the purpose of the enabling the State Government to efficiently ...

supervise manage and execute the work expeditiously as to subserve • the common good, in the context of the acute power shortage in the State. " In the impugned Act Section 4 provides for general effect of vesting. Section 5 provides that the State Government shall not be liable for past liabilities. Section 6 provides that notwithstanding anything contained in { Sections 3 and 4, the State Government may, if it is satisfied that the Board ""is willing to comply, or has complied with such terms and conditions as that Government may think fit to impose, direct by notification, that the undertaking I-I BHARAT HYDRO POWER CORPN. LTD. v. STATE [BllAN. J. J 291 t -r of the company and the righ( title and interest of the company in relation to its undertaking which has vested in the Government, vest in the Board either on the date of tlle notification or on such earlier or later date as may be specified in the notification.

The Board shall on and from the date of such vesting, be deemed to have become the owner in relation to such unde1taking and all the rights and liabilities of the State Government in relation to such undertaking shall, on and from the date of such vesting, be deemed to have become the rights and liabilities, respectively of the Board. ~ \' Section 7 provides for payment of compensation that may be fixed by the Commission considering the value of . the assets of the company after observing proper financial formalities. Section 8 provides for the gross amount payable to ! he company. Section 9 provides that the State Government if it is satisfied that the appellant has on or before the appointed day, disposed of any fixed asset whether by way of sale, exchange, gift, lease or otherwise than in the normal course of events, with a view to benefit the company or some other person unduly and thereby causing loss to the State Govemme.

nt as the succeeding owner of the company, the State Government shall be entitled to deduct such amount froin the amount payable to the Company under the Act. Section I0 provides for recovery of loss from the company. ~ Section 11 provides for certain deductions to be made from the gross amount payable. Section 12 provides for payment of net amount. Section 13 provides for recovery of excess amount. Section 14 provides for constitution of Commission. Section 15 provides for the continuance in service ofemployees already working on the same terms and conditions as were applicable to them earlier. Section 16 provides for provident fund and other funds. Section , 17 provides for making inventory of assets. Section 19 provides for penalty. Section 20 provides that no court shall take cognizance of an offence punishable under this Act except with the previous sanction of the State Government.

Section 22 provides that no suit against the State Government 1" or the Board shall lie for any act done by them in good faith or intended to .. be done in good faith in pursuance of the Act or the Rules made thereunder. Section 23 provides for bar of jurisdiction of the court to call in question any act done or purported to have been done under the Act or the Rules. Section 24 provides that no provision of the Indian Electricity Act, 1910, Electricity (Supply) Act, 1948 or any other Act for the time being in force and of any rule made under any of those Acts, shall, in so far as it is I inconsistent with any of the provisions of the Act, have. any effect. Section "' 26 provides for arbitration in case of any dispute arising in respect of the matters mentioned thereunder. )..

T; On completion of the pleadings, the writ petitions were placed for hearing before a learned Single Judge who after hearing the counsel for the parties, passed a detailed order striking down Sections 3, 4, 5, 6, 7, 7A,. 15(2), 23 and 24 of the Act being repugnant to the Ce. ntral Acts, i. e, the Indian Electricity Act, 1910 and the Electricity (Supply) Act, 1948: It was observed that because of the striking down of the various provisions, the impugned Act could not be given effect to. The entire Act was held to be unenforceable. The Board and the State of Assam filed separate Writ Appeals Nos. 460 of 1997 and 464 of 1997 challenging the order of the learned Single Judge. The Division Bench by its impugned judgment has set aside the judgment of the learned Single Judge and held the Act and its provisions to be intra vires of the Constitution. Resultantly the writ appeals were accepted and writ petition filed by the appellants were ordered to be dismissed.

Before adverting to the submissions made before us we would broadly refer to a few fundamental principles regarding the competence of the respective legislatures to enact iaws and as to which law would prevail in case of inconsistency between the laws made by the Parliament and the laws made by the State Legislature. The principles are being refen-ed to in the context of the controversy involved in the present appeals. India being a Union of States has Union Legislature (Parliament) and the State Legislatures for framing laws. Legislative fields in which the Union or the State legislatures can frame laws are prescribed in the three lists .. contained in the Seventh Schedule to the Constitution of India Union List (List I); State List (List If); and Concurrent List (List Ill ). Source of power for enacting laws relating to the three lists is to be found in Articles 245 and 246 of the Constitution of India.

Article 245 provides that subject to the provisions of the Constitution, Parliament may make laws for the whole or any part of the territory of India, and the Legislature of a State may make laws for the whole or any part of the State. Law made by the Parliament shall not be deemed to be inv~lid on the ground that it would have extra-territorial operation. Article 246 reads: "246. Subiect-matter of fall's made by Parliament and hy the legfalatures of States. -( I) Notwithstanding anything in clauses (2) and (3), Parliament has exclusive power to make laws with respect to any of the matters enumerated in List I in the Seventh Schedule (in this Constitution referred to as the "Union List"). BHARAT HYDRO POWER CORPN. LTD. v. STATE [Bl-IAN, J.

) 293 ) -r (2) Noiwithstanding anything in clause (3), Parliament and, subject to clause (I), the Legislature of any State also, have power to make laws with respect to any ofthe matters enumerated in List Ill in the Seventh Schedule (in this Constitution referred to as the "Concurrent List"). (3) Subject to clauses (I) and (2), the Legislature of any State has exclusive power to make laws for such State or any part thereof with respect to any of the matters enumerated in List II in the Seventh > i Schedule (in this Constitution referred to as the 'State List'). (4) Parliament has power to make laws with respect to any matter for any part ofthe territory of India not included in a State notwithstanding that such matter is a matter enumerated in the State List. " Without going into the finer aspects but broadly speaking it provides that Parliament has exclusive power to legislate with respect to matters in List I.

The State Legislature has exclusive power to legislate in respect to matters in List II. Both Parliament and the State Legislature have power to make laws with respect to any ofthe matters enumerated in List Ill. In a federal Constitution, in which there is a division of legislative ·"' powers between the Central and the Provincial Legislatures, controversies often arise as to whether one or the other legislature is not exceeding its legislative power, and encroaching on the other's constitutional legislative power. To resolve the dispute as to which law would prevail in a case where both the Union as well as the State Legislature have the competence to enact laws, A11icle 254 provides that if any provision of a law made by the Legislature of a State is repugnant to any provision of law made by Parliament which Parliament is competent to enact, or to any provision of an existing _...

law with respect to one of the matters enumerated in the Concurrent List, ' then, subject to the provisions of clause (2), the law made by Parliament shall • prevail and the law made by the Legislature of the State shall to the extent of the repugnancy be void. Clause (2) provides that where a law made by the Legislature of a State with respect to one of the matters enumerated in the Concurrent List contains any provisions repugnant to the provisions of an earlier law made by the Parliament or an existing law with respect to the matters, then, the law so made by the Legislature of such State shall, if it has been reserved for the consideration of the President and has received his assent, prevail in that State. . ,. , It is likely to happen from time to"time that enactment though purporting to deal with a subject in one list tQuches also on a subject in another list and prima facie looks as if one legislature is impinging on the legislative field of the another Legislature.

This may result in large . number of statutes being declared unconstitutional because the legislature enacting law may appear to have legislated in a field reserved for the other legislature. To examine whether a legislation has impinged in the field of other legislatures, in fact or in substance, or is incidental, keeping in view the true nature of the enactment, the Courts have evolved the doctrine of"pith and substance" for the purpose of determining whether it is legislation with respect to matters in one list or the other. Wh . ,.. "When the question is whether a provincial legislation is repugnant to an existing Indian Law, the onus of showing its repugnancy and the extent to which it is repugnant should be on the party attacking its validity.

There ought to be a presumption in favour of its validity, and every effort should be made to reconcile them and construe both so as to avoid their being repugnant to each other; and care should be taken to see whether the two do not really operate in different fields without encroachment. fu1ther repugnancy must exist in fact, and not depend merely on a possibility: Their Lordships can discover no adequate grounds for holding that there exists repugnancy between the two laws in districts of the "" province of Ontario where the prohibitions of the Canadian Act are not and may never be in force: (1896) AC 348 at pages 369-370. " It was conceded by the learned counsels appearing on both sides that this view has been accepted and reiterated by this Court in a number of judgments. It is not necessary to refer to all those cases which would be repetitive only.

Though in the High Court (both before the learned Single Judge as well as Division Bench) and in the special leave petition number of points were taken/argued but before us the submissions were limited to three _,.. points to which reference would be made in the subsequent paragraphs. Before adverting to the actual submissions made by the respective learned counsds, entries in the three lists relating to generation of power/ electricity and acquisition may be noticed, which read: Entry 56 of List /: Regulation and development of inter-State rivers and river valleys to the extent to which such regulation and development under the control of the Union is declared by Parliament by law to be expedient in the publiC interest. , ).. t' • Entry 17 of list II: Water, that is to say, water supplies, irrigation and canals, drainage and embankments, water storage and water power subject to the provisions of entry 56 of List I.

Entry 38 of List Ill: Electricity; Entry 42 of list ///: Acquisition and requisitioning of property. 'r • It was conceded before us that Entry 56 List I would not be applicable. Learned Single Judge held that the Act enacted by the Assam Legislature would fall under Entry 38 of List Ill. Since the Parliament had already enacted compre:1ensive laws regarding the generation and supply of electricity by enacting the Indian Electricity Act, 1910 (hereinafter referred to "Act of 191O") and the Electricity (Supply) Act, 1948 (hereinafter referred to "Act of 1948") covering the entire field, the field being occupied, the State Legislature did not have the competence to enact the laws under Entry 38 of List Ill. As the Act pass l' Legislature. On the other hand, Mr. Vijay Hansaria, learned senior counsel appearing for the State of Assam as well as the Board contended that the impugned Act was not repugnant to the provisions of the Central Acts.

According to him, impugned Act and the Central Acts in the instant case operate in two different fields without encroaching upon each others field in as much as the true nature and character of th~ impugned State Act is to acquire the undertaking, whereas both the Central Acts have made general provisions with regard to supply and use of electrical energy. It was vehemently contended that there was no violation of Sections 3, 4, 5, 6, 7 and 7A of the Act of 1910, by Sections 3 and 4 of the impugned Act as the appellants were not 'licensees' under the Act of 1910 and the State Government had the jurisdiction and ·"" power to acquire any property for public purposes making necessary provisions for payment of compensation. That the impugned Act has taken adequate care for payment of compensation after proper assessment by the Commission to be constituted by the authority.

There is no direct conflict between the provisions of the Central Act and the State Act bringing a position where one cannot be obeyed without disobeying the other and the impugned Act and the Central Act both can stand together even though the State law may provide for certain additional/supplementary provisions. In substance the submission made is that in pith and substance the State Act is not repugnant to the --' Central Acts as the two sets of Acts operate in different fields. Learned counsel appearing for the appellants placing reliance on Constitution Bench decision of this Com1 in Deepchandv. State'o/U. P. , AIR (1959) SC 648, contended that even in the absence of direct conflict, the State law would be inoperative as the Central Acts of 1910 and 1948 intended to be exhaustive Codes in the field of electricity and the State Legislature did ... , J not have the legislative competence to enact law in the field occupied by the Central Legislation. Law .

made by the State Legislature in the occupied field could not come into operation unless it was reserved for the assent of the "' President of India and assented by him in terms of Article 254 (2). Ii was observed in para 29: "Nicholas in his Australian Constitution, 2nd Edn. Page 303, refers to three tests . of inconsistency or repugnancy: (I) There may be inconsistency in the actual terms of competing statutes; (2) Though there may be no direct conflict, a State Law may be r , inoperative because the Common Wealth Law, or the award of th€: Common Wealth Court, is intended to be a complete exhaustive Code; and (3) Even in the absence of intention, a conflict may arise when both State and Common Wealth seek to exercise their powers over the same subject matter. This Court in Tika Ramji v. State ofUttar Pradesh, [1956] SCR 393: (S) AIR (1956) SC 676 accepted the said three rules, among others, as useful guides to test the question of repugnancy. In Zaverbhai Amaidas v.

State ofBombay, [1955] I SCR 799: AIR (1954) SC 752, this Court laid down a similar test. At page 807 (of SCR): (at p. 757 ,,,. of AIR), it is stated: "The principle embodied in section I07 (2) and Article 254 (2) is that when there is legislation covering the same ground both by the centre and by the Province, both of them being competent to enact the same, the law of the Centre should prevail over that of the State. " Repugnancy between two statutes may thus be ascertained on the basis of the following three principles: (1) Whether there is direct conflict between the two provisions; (2) Whether Parliament intended to lay down an exhaustive code in respect of the subject matter replacing the Act of the State Legislature; and (3) Whether the law made by Parliament and the law made by the State Legislature occupy the same field. " This Court laid down three broad principles to find out whether there is any Rcpugnancy between the two statutes, i. e.

, whether there is a direct conflict between the two statutes, whether the two statutes occupied the same field BHARAl" llYDRO POWER CORPN. LTD. v. STATE [BHAN. J. ] 299 and as to whether the Parliament intended to lay down an exhaustive code in ' -... / respect of the subject matter. In M. Karunanidhi v. Union of India, AIR (1979) SC 898, Fazal Ali, J. reviewed the authorities on repugnancy under. Article 254 and held that the '· following propositions emerged from decided cases: "I. That in order to decide the question of repugnancy it must be shown that the two enactments contain inconsistent and irreconcilable .. , ~ provisions so that they cannot stand together or operate in the same field. 2. That there can be no repeal by implication unless the inconsistency appears on the face of the two statutes. 3.

That where the two statutes occupy a particular field, but there is room or possibility of both the statutes operating in the same field without coming into collision with each other, no repugnancy results. 4. That where there is no inconsistency but a statute occupying the same field seeks to create distinct and separate offences, no question of repugnancy arises and both the statutes continue to operate in the ~ same field. " Without entering into the controversy whether the State Act would fall under Entry 17 of List II or under Entry 38 of List Ill and assuming (but not holding that it falls under Entry 38 of List Ill) we examine as to whether there is any conflict between the provisions of the Central Act and the State Act. If there is no conflict at all the question of repugnancy would not arise. The State Act has been enacted to take over the Bharat Hydro Power Corporation in public interest as it could not complete the project within time ....

so that the State could efficiently supervise manage and execute the work expeditiously to subserve the common good, in the context of the acute power shortage in the State. The State after taking over the project had the power to hand it over to the Board for completing the project. Provision has been made to pay adequate compensation which is to be determined by Commission constituted under the Act for payment ofadequate compensation. Contention raised on behalf of the appellants is that Central Act makes specific -. , provisions for compulsory purchase of undertuking and a detailed procedure has been prescribed and the State Act has created a parallel procedure for purchase of the undertaking thereby impinging on the Central Act and is ) therefore repugnant to the Central Act. We do not find any substance in this r , submission. The Act of 1910 relates to the supply and use of electrical energy.

Section 3 provides that the State Government may on an application made in the prescribed form and on payment of the prescribed fee (if any) grant a license to supply energy in any specified area and also to lay down or place electric supply lines for the conveyance and transmission of energy. Section 4 speaks of revocation or amendment of licenses under the specified conditions. r , Section 4A speaks of the amendment of licenses. Section 5 makes provisions where license of a licensee is revoked. Section 6 relates to purchase of undertakings. Section 6 of the Act of 1910 reads: "6. Purchase ofunder/akings.

- (I) Where a license has been granted to any person, not being a local authority, the State Electricity Board shall,-· (a) in the case of a license granted before the commencement of the Indian Electricity (Amendment) Act, 1959 (32 of 1959) on the expiration of each such period as is specified in the license; and 3 (b) in the case of license granted on or after the commencement of the said Act, on the expiration of such period not exceeding thi1iy years and of every such subsequent period, not exceeding twenty years, as shall be specified in th is behalf in the license, have the option of purchasing the undertaking and such option shall be exercised by the State Electricity Board serving upon the licensee a notice in writing of not less than one year requiring the licensee to sell the undertaking to it at the expiry of the relevant period referred to in this sub-section.

(2) Where a State Electricity Board has not been constituted, or if constituted, does not elect to purchase the undertaking, the State Government shall have the like option to be exercised in the ·like manner of purchasing the undertaki1ig. (3) Where neither the State Electricity Board nor the State Government elects to purchase the unde11aking, any local authority constituted for an area within which the whole of the area of supply is included shall have the like option to be exercised in the like manner of purchasing BHARAT HYDRO POWER CORPN. LTD. v. STATE [BllAN. J. ] 301 ·i the undertaking.

(4) If the State Electricity Board intends to exercise the option of purchasing the undertaking under this section, it shall send an intimation in writing of such intention to the State Government at least eighteen months before the expiry of the relevant period referred to in sub-section (I) and if no such intimation as aforesaid is received by the State Government the State Electricity Board shall be deemed to have elected not to purchase the undertaking. 1 ' (5) Ifthe State Government intends to exercise the option of purchasing the undertaking under this section, it shall send an intimation in writing of such intention to the local authority, if any, referred to in subsection (3) at least fifteen months before the expiry of the relevant period referred to in sub-section (I) and if no such intimation as aforesaid is received by the local authority, the State government shall be deemed to have elected not to purchase the undertaking.

(6) \\'here a notice exercising the option ofpurchasing the undertaking has been served upon the licensee under this section, the licensee shall deliver the undertaking to the State Electricity Board, the State Government or the local authority, as the case may be, on the expiration of the relevant period referred to in sub- section (I) pending the determination and payment of the purchase price. (7) Where an undertaking is purchased under this section, the purchaser shall pay to the licensee the purchase price determined in accordance ~ with the provisions of sub-section (4) of section 7A. " Section 4 which provides for revocation or amendment of licenses. Section 4A which provides for amendment of licenses at the instance of the . Jr licensee or otherwise and Section 5 which enumerates the procedure to be followed where the Government revokes the license under Section 4 would not be attracted/applicable as the appellants are admittedly not licensees.

These provisions would apply to . licensees only. Section 6 is again applicable to licensees only. It is not applicable to sanction holders. It talks of preemptory right of the Board to purchase the undertaking on the expiry of the period mentioned in clauses (a) and (b) of Section 6 which can be done after . serving upon the licensee a notice in writing of not less than one year requiring Jt ~ the licensee to sell the unde11aking to it at the expiry of the period referred to in clauses (a) and (b) of Section 6. Section 6 (7) provides for payment of purchase price by the purchaser to the licensee determined in accordance with the provisions of Section 7A. Since" the appellants have not been given r , license and are not 'licensees', Section 6 would not apply. Under Section 6 there is an 'option' with the Board to purchase. The word 'option' leaves two courses open to the authority, i. e. , either to purchase an undertaking or to renew the license.

Either of the two courses would not be available as the appellant No. I is not a licensee. Section 7A which deals with the determination of purchase price again y talks of where an undertaking of a licensee is purchased. Since the appellants are not the licensees they would not be covered un. der any of the provisions dealing with the sale or purchase of undertaking as provided under the Act of 1910. The benefit of Sections 7 and 7A shall also not be available because it speaks of an undertaking of a licensee. As the appellants are not covered by the provisions of the Act of 1910 the question of the State Act which seeks to take over the appellants' undertaking and make provisions for compensation would not be repugnant to any of the provisions of the Act of 1910.

Submission made by the learned counsel for the appellants that the State Act creates procedure parallel to the existing procedure provided under Section 6 of the Act of 1910 or for determing the purchase price as provided under Section 7A cannot be accepted because the provisions of Chapter 11 (Sections 3 to 11) are not applicable to the appellants as they are not licensees. Faced with this situation Mr. V. R. Reddy, learned senior counsel for the appellants, submitted that the appellants are deemed licensees under the provisions of Act of 1948. For this he has referred to Section 26A of the Act of 1948. Section 26A reads as: "26A. Applicability ofthe provisions ofAct 9of1910 to Generating Company. -( 1) Notwithstanding anything contained in sub-section (2), nothing in the Indian Electricity Act, I910, shall be deemed to ...

•'" require a Generating Company to take out a licence under that Act, or to obtain sanction of the State Government for the purpose of carrying on any of its activities. (2) Subject to the provisions of this Act, Sections 12 to 19 (both inclusive) of the Indian Electricity Act, 1910 (9of1910) and clauses XIV to XVII (both inclusive) of the Schedule thereto, shall, as far as ... may be, apply in relation to a Generating Company as they apply in V' relation to a licensee under that Act (hereafter in this section referred to as the licensee) and in particular a Generating Company may, in connection with the performance of its duties, exercise- BHARAT HYDRO POWER CORPN. LTD. "· STATE [BHAN. J. ] 303 ~ i (a) all or any ofthe powers conferred on a licensee by sub-section(!

) of Section 12 of the Indian Electricity Act, 1910, as if- (i) the reference therein to licensee were a reference to the Generating Company; (ii) the reference to the terms and conditions of licence were reference to the provisions of this Act and to the articles of association of the Generating Company; and ' .. ,. (iii) the reference to the area of supply were a reference to the area specified under sub-section (3) of section J5A in relation to the Generating Company; (b) all or any ofthe powers conferred on a licer. see by sub-section (I) of section 14 of the Indian Electricity Act, 1910 (9of1910), as if- (i) the references therein to licensee were references to the Generating Company, and (ii) the Generating Company had the powers of a licensee under the said Act. (3) The provisions of section 30 of the Indian Electricity Act, 1910 (9 of 1910) shall not apply to the transmission or use of energy by, a Generating Company.

(4) For the removal of doubts, it is hereby declared that sections 3I to 34 (both inclusive) of the Indian Electricity Act, 1910 (9of1910) shall apply to a Generating Company. " Section 26A provides that notwithstanding the provisions ofSub-Section (2) a generating company would not be required to take a licence under the ' A' Act of 1910 or to obtain sanction of the State Government for the purpose ofcarrying on any of its activities. Under sub-section (2) provisions ofSections 12 to 19 of the Act of 1910 are made applicable to a generating company as they apply to a lie. ensee under the 1910 Act. It is to be noted that provisions of Sections 3 to 11 of 1910 Act have not been made applicable to the generating company.

"Generating Company" has been defined in Section 2(4A) of the 1948 Act to mean: "'Generating Company' means a company registered under the t' • Companies Act I956 (I of 1956) and which has among its objects the establishment operation and maintenance of generating stations" ''Licensee" has been defined under this Act in Section 2(6) as under: " "licensee" means a person license under Part II of the Indian Electricity Act, I9 I0 (9 of I9I0) to supply energy or a person who has obtained sanction under Section 28 of that Act to engage in the business of supplying energy but the provisions of Section 26, or -,.. 26A of this Act notwithstanding, does not include the Board or a Generating Company. " A combined reading of Sections 2(4A) and 2(6) makes it clear that even ifthe appellant No.

I is taken to be a generating company (which is not necessary to be determined in this case) it would not be a 'licensee' because the generating company has been specifically excluded from being a licensee notwithstanding the provisions of Sections 26 or 26A of the I948 Act. As pointed out earlier only Sections 12 to 19 of the Act of 1910 have been made applicable to a generating company. Sections 3 to 11 of Act of 1910 do not apply to a generating company. Section 37 of Act of 1948 provides for purchase of generating stations or undertakings or main transmission lines by the Board. This Section would also not apply to the present case. The legislature in its wisdom made only certain provisions of Act of 1910 applicable to a generating company in Section 26A. Contention that the impugned Act is in violation of provisions ..... of Act of 1910 or the Act of 1948 has no basis to stand on. The impugned Act and the Central Acts in the instant case operate in i.

vo different fields without encroaching upon each other's field in as much I as the true nature and character of the impugned State Act is to acquire the . ,. _ undertaking and pay compensation as provided in the Act whereas both the Central Acts (Acts of 19 I0 and 1948) have made general provisions with regard to supply and use of electrical energy. The provisions regarding purchase of unde11aking in the Act of 1910 would not be applicable as the appellants are not licensees within the meaning of the Act of 1910. There is not even a semblance of conflict what to talk of direct conflict between the impugned State Act and the Central Acts to bring about the situation where one cannot be obeyed without disobeying the others. Both the Acts can operate simultaneously as they do not occupy the same field. As the enactments. operate in two different fields without encroaching upon each other's field . (~ BHARAT HYDRO POWER CORPN. LTD. v. STATE (BHAN, . I. ] 305 there is no repugnancy.

A Since there is no repugnancy the question of the State Act being kept for the consideration of the President or receiving his assent did not arise. For the reasons stated above, we do not find any merit in these appeals and the same are dismissed. Parties shall bear their own costs in these appeals. B B. S. Appeals dismissed. r 1 ; >